福建省汽雾笛招标公告（福建省船舶工业集团有限公司2025）
MW651-1/2 汽雾笛
发布日期：2025-11-14
发布企业：福建船政
截止时间：
2025-11-18 23:59:00
报价倒计时：
4
天
14
时
45
分
报价中
基本信息
发布企业：
福建船政
采购类别：
气雾笛(含：电笛喇叭)
采购编号：
FJCZCG202511223
报价时间：
2025-11-14 08:43 至 2025-11-18 23:59
经办部门：
采购中心
经办人员：
康磊鑫
采购内容
MW651-1/2 汽雾笛
附件列表
230713国内合同样本-东南.doc
230713进口合同样本-东南.doc
FSMW651-TA-E01-01 汽雾笛 技术协议-华杰西_Signed.pdf
船政询价函-样本251030.docx
我要报价
福建东南造船有限公司产品购销合同合同编号：签约地点:福州所用船舶及型号：买方：福建东南造船有限公司联系地址：福建省福州市马尾区建设路7号联系人及电话：联系人邮箱：卖方:联系地址:联系人及电话：联系人邮箱：鉴于买方在建船舶需求，就买方向卖方购买产品，卖方提供产品和服务等事宜，现根据《中华人民共和国民法典》等相关法律规定，经双方平等协商后，达成如下条款：1.产品概况:注：上述产品应满足买卖双方于年月日签订的技术协议（编号：）序号产品名称型号规格单位数量单船价贰船金额备注1船套合同总价：元（大写：人民币元整），不含税金额为:元(大写)，增值税税款为:元(大写)（注：该固定总价已包含产品制作费、包装费、运输费、调试费、船检费、13%税率等到厂价，买方无需就本合同再额外支付其他费用）备注：合同执行过程中若遇增值税税率调整，双方将根据国家财政局、税务总局颁布的相关通知、文件规定的最新增值税税率来调整合同金额，最终合同金额根据不含税总价和实际开具的增值税专用发票的税率来确定序号产品名称型号规格单位数量单船价贰船金额备注1船套合同总价：元（大写：人民币元整），不含税金额为:元(大写)，增值税税款为:元(大写)（注：该固定总价已包含产品制作费、包装费、运输费、调试费、船检费、13%税率等到厂价，买方无需就本合同再额外支付其他费用）备注：合同执行过程中若遇增值税税率调整，双方将根据国家财政局、税务总局颁布的相关通知、文件规定的最新增值税税率来调整合同金额，最终合同金额根据不含税总价和实际开具的增值税专用发票的税率来确定在本产品履行过程中，买方增减采购产品数量的，除双方另行书面约定外，价格仍按本合同约定价格执行，合同期内产品单价不因任何原因而调整。二.交货方式、日期及地点：1.卖方应在年月日前将全部产品交付至福建省福州市连江县琯头镇粗芦岛大道3号。在卖方发货前1个月，买方有权以电邮方式通知卖方变更交货时间、数量及地点。卖方对此表示认可并承诺不因买方变更交货时间、地点、数量而额外收取费用。2.卖方负责将产品运至买方所指定地点，并在产品装运后1日内将合同号、品名、件数、重量、运输工具名及装运日期以邮件方式通知买方，卖方对产品的包装应符合国家有关规定。三.资料交付、包装要求：1.卖方提供的制造工厂的品质及数量、重量证明书，批号须与产品一致。2.所供产品的技术规格与双方签订的技术协议规定的标准相一致，若技术协议中无相应规定，产品应符合合同签字时施行的船级社和国家（有关部门）的标准。3.技术规格书上所要求的资料要和相应的材料（包括但不限于产品认可图、产品工作图、产品完工图）应一并装箱,并在装箱单上注明。4.产品证书：按照双方技术协议要求在产品交付后30日内以邮寄方式向买方提供。5.装箱单及/或重量单：发货前1日将发货清单等单据以邮件的方式提供给买方，发货清单上必须注明合同号，并详细列出产品总箱数，每箱内所装产品的名称及数量，并将此清单放在每个包装箱内，并粘贴一份在包装箱外。发货的包装要求有效保护货物安全、防止破损、生锈等情况的发生；装箱时要求分类、分规格进行包装；要求达到清楚分类、高效清点的目的。6.卖方保证其供应的所有产品不含石棉材料，并在产品到达目的地3个工作日内向买方提供“无石棉声明”(按买方要求的格式)或有检测资质的第三方检测报告等支持文件。若买方发现卖方所供产品含有石棉材料的，由此引起的所有责任及损失均由卖方承担，包括但不限于买方被要求做全船的无石棉检测所发生的费用及损失责任。若在买方交船后发现上述情况，卖方仍须承担由此引起的所有责任，此责任并不受质保期限及合同其他损失索赔条款的限制。7.对于特殊产品（如易燃、易爆）必须特别标明其品名、性质、特殊保护措施、保存办法以及处理意外情况的办法。8.卖方必须按下列格式，在每个包装箱外做好标识。收货人：福建省马尾造船股份有限公司收货人地址：福建省福州市连江县琯头镇粗芦岛大道3号采购员及电话：船号或合同号：设备名称：若卖方逾期履行上述任何义务，每逾期一周则按款项总额的1%向买方支付违约金，不足一周按一周计算，每项义务逾期履行的违约金最多不得超过款项总额的10%，但卖方已经完成货物生产制造具备交货条件而不交货按照本合同第八条约定执行。四.付款条件与结算方式：（一）双方约定按以下方式进行付款：见招标文件（二）本条款款项结算方式按如下第1种方式办理：1.以银行转账方式结算；2.以银行承兑汇票（承兑日期为汇票确认之日起个月）结算。（三）本条款关于质保金的收取，若买方另行书面同意卖方以提供等额质保函替代合同总价10%质保金时，买方应在最后一笔款项结算时一并支付。（四）本合同款项结算时，若因卖方违约或造成买方损失时，买方有权在书面告知卖方扣减事由后直接扣减相应地款项，卖方对此表示认可。（五）双方指定银行及纳税人识别号（四）买卖双方银行等单位信息1.买方开票资料（若有变更另行通知）：单位名称：福建东南造船有限公司纳税人识别号：91350000158145306W地址及电话：福建省福州市马尾区建设路7号、0591-83985085开户行及账号：交通银行福建省分行、3510080100100100001292.卖方指定收款银行：开户行及账号：五.保险：由卖方按中国人保运输产品保险条款按发票金额的110%投保一切险。如果发生保险范围内的索赔,卖方应根据买方要求,重新发运本合同下的产品或采取其他措施,保证买方的生产不受影响。若发生保险事故造成逾期到货的，卖方仍应按本合同约定承担违约责任。六.交付和检验：1.在发货前，卖方应对全部产品的质量、规格、性能、型号、数量和重量等进行准确而全面的检验，FAT实验前一周卖方向买方指定邮箱发出邮件通知，并告知FAT实验的具体日期、实验流程及项目2.卖方将产品运送至目的地后，买方签收时若产品的数量、外观等与送货清单相符，则买方签收确认，否则买方有权拒收产品，拒收产品之日起产品灭失或毁损的风险由卖方承担。签收后30日内，买方应进行来货检验，若卖方需参与来货检验，买方应在来货检验前书面通知卖方参与检验，若卖方收到通知后未参加检验，视为认可买方检验结果。来货检验完毕后，若产品验收合格，视为卖方完成产品交付；若检验不合格，买方有权根据本合同第八条第二款的约定采取救济措施，卖方应在三个工作日内按照买方提出的解决办法予以解决，造成交货延误的，按照逾期交货处理。产品表面验收合格并不意味着对卖方全部产品的质量等确认。3.产品安装后，卖方应根据买方规定时间对产品进行调试（若有），调试完毕后，由买卖双方组织产品验收。七、不可抗力由于不可抗拒事故,使卖方不能在合同规定期限内交货或不能交货,卖方不负责任，但卖方应在24小时内以邮件通知买方,并在五天内以挂号函向买方提供有关政府机构或者商会所出具的证明,以证明事故的存在。由于不可抗拒事故致使交货延期超过30天以上时,买方有权解除合同，并要求卖方退还买方已支付但未能交货的款项，卖方应在收到买方解除合同通知后5个工作日内退还款项。但若因卖方迟延履行期间发生的不可抗力不具有免责效力。八、违约责任1.除本合同第七条不可抗拒原因外,卖方不能如期交货或提供服务应在24小时内以书面形式将不能按时交货或提供服务的理由、可能延误的时间同时通知买方。根据具体情况决定是否延长交货时间或解除合同并按照下列方式要求卖方承担责任：（1）在买方要求卖方继续履行合同的情况下，卖方应立即采取一切有效措施积极补救。若实际产生逾期，自本合同第二条约定的交货日期始，卖方每逾期交货一日应向买方支付合同总金额1%的违约金。若卖方不能在买方同意的交货时间内交货，则买方有权解除合同或向第三方采购同种类货物，卖方应承担由此给买方造成的全部损失并按合同总价的30%向买方支付违约金。（2）买方有权直接解除合同，卖方应退还买方已支付价款及利息并承担由此给买方造成的全部损失（上述利息应从买方付款之日起按照中国人民银行同期贷款利率计算至卖方退还款项及利息止（下同）、买方退货之日起产品灭失或毁损的风险由卖方承担）；2.在合同规定的检验期和质量保证期内，产品不符合合同约定或双方技术协议书约定，买方可选择的下列一种或多种方式解决：（1）买方选择退货的，卖方应退还已付款项及利息，并承担由此发生的一切损失和费用（包括但不限于：利息、银行手续费、运费、保险费、检验费、仓储费、装卸费以及为保护退回产品所需的其它必要费用）；（2）支付因此增加的费用，包括但不限于买方或买方指定的第三方进行检查、返工、重新测试、储存、装运、重新包装、重新安装、赶工和替换不良产品所产生的费用；（3）根据产品的低劣程度、损坏程度以及买方所遭受损失的数额，卖方降低供货价；（4）用符合要求的规格、质量和性能等新材料来更换有缺陷的部分，卖方应承担由此产生的一切费用和风险，并承担买方所蒙受的全部损失费用。同时，卖方应按合同规定，对更换件相应延长质量保修期；根据本条款约定，如果在买方发出索赔通知后2天内卖方未作答复，上述索赔应视为已被卖方接受，如卖方未能在买方提出索赔通知后7天内，按照买方选择的方法解决索赔事宜，买方有权将从卖方履约保函（若有）、款项中扣减相应的索赔金额，不足部分由卖方承担。本合同所指卖方给买方造成的全部损失包括但不限于：直接损失、预期利益损失、买方应向其他客户支付的违约金和赔偿金、买方使用其他供应商产品代替卖方未交付的合同产品而产生的全部费用（包括但不限于产品价格的差异、停工待料费用及赶工费）、买方为索赔而支出的诉讼费、保全费、律师费、公证费等必要的费用。3.除卖方原因外，若买方在规定时间内未向卖方支付款项，每逾期支付一日按照中国人民银行同期贷款利率计算利息，但利息总额不得超过未付款项的20%。九、附随义务1.卖方应在质保期限内对所提供产品实施更换、维修，但是该服务并不免除卖方在质量保证期内应承担的义务。2.如产品中需要安装调试等服务：【根据业务情况选择】（1）买方应该按照卖方的操作指导进行产品安装，并应向买方提供设备的使用指导说明。（2）安装后，卖方应检查设备运行状态，直到能够正常使用为止。（简称“调试”）如果设备没有达到正常使用状态，买方可以要求卖方重新调试。（3）在调试/试航期间，卖方应提供合适的劳动力、工作服、鞋子、安全帽、工具和材料等，买方可以提供必要的协助。（4）买方应至少在7天前通知卖方调试/试航日期。卖方应严格按照买方的通知安排人员到船厂服务。如果卖方未能及时安排人员提供服务，那么应向买方支付X元/天，并且买方保留索赔的权利。除非另有要求，卖方应指定有经验和称职的服务人员在买方工作日内提供现场调试/试航服务。但如服务人员不称职或缺乏经验，服务时间免费延长，直至工作成功完成为止。如果卖方想安排学员在买方学习，学员的培训时间不能计入服务时间。（5）卖方将提供单船总共X次X人天的免费调试/试航服务。超过合同规定的服务期限的服务费，按下列规定执行：船厂调试（每天8小时）每人每天X元。试航（每天16小时）每人每天X元。（6）因卖方原因导致部件丢失或损坏，或者服务时间浪费，不应计入合同服务时间。如果服务人员在船上的工作时间不足8小时（不包括路途时间），卖方应予以补充或在最终结算中扣除。（7）如果单船合同的免费服务时间没有用完，卖方同意将剩余的时间转让给同系列姊妹船。（8）在服务期间，服务人员应遵守买方适用于工作现场的安全生产规章制度和当地法律。服务人员应遵守买方的工作时间，不允许迟到或早退。工程进度紧张时，服务人员会配合并协助买方完成紧急工作。服务人员在买方所在地的安全责任应由卖方负责。十、权利担保及质量保证1.卖方保证本合同产品及其包含的组件和零件均为全新，每件合同产品均无瑕疵，完全符合本合同及技术协议规定的质量和规格，且产品权利不存在任何瑕疵，保证买方在使用该产品或其任何一部分时不受第三方提出侵犯权利的起诉。一旦出现侵权，由卖方承担全部责任。如造成买方损失的，买方有权向卖方追偿。2.产品质量保证期限自买方交船后起算保修期为十二个月。在保修期内，卖方可支持的保修范围（全球联保/全国联保），对由于设计、工艺或材料的缺陷而发生的任何不足或故障负责，卖方须承担由此产生的一切损失和责任，包括但不限于修理、更换、产品运输及重新安装、专家咨询、质保差旅等费用。如果在保修期内对发现的一般缺陷，乙方应及时修理或替换机器/配件等，针对新换上的机器/配件乙方应提供额外六个月的保修期，或更换的机器/配件与整个产品总共有十八个月的保修期。因设备重大缺陷、故障和损坏导致整机更换后，该设备的保修时间自更换并验收合格之日起重新计算。3.在保修期内或经有关部门检验，产品的质量或规格与合同不符，或产品有缺陷，包括潜在的缺陷或是使用不符合要求的材料等，买方以书面形式向卖方索赔。4.对于产品隐蔽性的、通过合理的检查和试验都不能发觉的缺陷，即使质量保修期已过，但由于产品本身的设计缺陷、制造缺陷、安装缺陷造成的故障，仍由卖方免费修复。4.卖方在收到买方有关卖方所提供产品的质量问题通知后，应在12小时内响应，24小时内解决一般问题，48小时内解决疑难问题。确实需要一定供货周期的特殊部件更换时，卖方应以书面形式向买方申请，获得许可后方可延长时间。若卖方在收到买方有关卖方所提供产品的质量问题通知后，怠于履行上述义务，买方有权委托第三方予以解决，由此而产生的一切费用和风险由卖方承担。买方有权直接从质保金中扣减因此产生的一切费用，不足部分由卖方承担。5.卖方因供货质量问题给买方造成重大经济损失或责任事故的，卖方应赔偿买方损失，构成责任事故的，由司法机关追究卖方的法律责任。十一、合同终止1.当卖方破产、停产或其他无清偿能力时，买方可在任何时候以书面通知卖方终止合同，该终止合同以不损害或影响买方已采取或将采取补救措施的任何权利为条件。2.在买方对卖方违约而采取的任何补救措施不受影响的情况下，买方可向卖方发出终止部分合同或全部合同的书面通知书。十二、争议解决因本合同引起的或与本合同有关的任何争议，双方应先友好协商解决，若协商不成的，双方选择按下列第2种方式解决：1.提交福州仲裁委员会仲裁，仲裁裁决是终局的，对双方均具有约束力；2.依法向买方所在地人民法院提起诉讼十三、通知及送达1.买卖双方确认本合同中各提供的地址、联系方式、邮箱系本合同履行及相关事宜的通知、文件，以及仲裁机构、法院与国家机关因本合同争议及/或裁决执行发出的通知和法律文书的唯一送达地址、通讯方式。一方变更上述地址、联系方式、邮箱的，应在24小时内书面通知对方；若因一方未按时通知对方，对方及仲裁机构、法院或国家机关按照原地址、原通讯方式送达，无论是否退回均视为送达。2.按本合同约定由任何一方发给其他方的任何通知或者书面通讯，包括但不限于本合同约定必须发出的任何及所有书面文件或通知，如采用挂号邮寄方式，上述文件或通知在投邮后第4日，即视为送达和收到之日；如采用图文传真方式，发送成功回执所示之日，即视为送达和收到之日；如采用特快专递方式，专递人员将上述文件或通知送达收件人地址之日，即视为送达和收到之日。十四、安全生产条款1.卖方为履行合同义务，派遣至买方相关人员（统称服务人员）；必须随身携带工作服、安全帽、安全鞋、安全带等劳动防护用品；服务人员需具备相应的资质，以确保工作的顺利完成；卖方必须告知服务人员严格遵守买方的规章制度，不得违反。2.卖方服务人员到达买方，必须接受买方的安全教育，仔细阅读《外来人员（临时人员）安全告知》并签署《三级安全教育登记表》。未完成安全教育、未签署《三级安全教育登记表》的人员严禁上岗。3.卖方服务人员需服从买方的安全管理，若卖方服务人员拒绝安全教育或违反买方安全生产等规章制度，买方有权要求卖方更换服务人员，并要求卖方承担因此对买方造成的损失。4.卖方作为服务人员的第一安全责任人，除为服务人员购买相应的保险外，还必须加强对服务人员的安全教育，加强安全意识，确保其不违反《安全生产法》、《安全生产违法行为行政处罚办法》、《能源法》、《环保法》和买方相关管理规定。5.若卖方服务人员不遵守买方相关管理规定、违反操作规程等，造成安全生产事故的、或对服务人员造成人身伤害的，相关责任将由卖方承担不由买方承担。十五、其他事项1.本合同签订及履行过程中，未经买方书面同意，卖方不得将本合同的权利义务以任何方式转让给第三方，否则买方有权单方解除本合同并要求卖方承担因此给买方造成的全部损失和向买方支付合同总价30%的违约金。2.本合同自双方签字盖章后生效至双方全部权利义务履行完毕后自行终止，一式三份，卖方一份，买方两份，均具有同等法律效力。3.本合同如有未尽事宜，双方另行协商。买方：福建东南造船有限公司卖方：授权代表：授权代表：签署日期:2023年月日后附:附件1.物资采购廉政责任书；附件2.合同清单福建东南造船有限公司物资采购廉政责任书(合同附件)为加强物资采购的廉政建设，规范买卖双方之间的各项活动，防止发生任何谋取不正当利益的违法违纪行为，保护买卖双方的合法权益，特签订本廉政责任书。第1条买卖双方的廉政责任（一）应严格遵守国家关于市场活动的有关法律、法规和相关政策，以及廉政建设的各项规定。（二）业务活动必须坚持诚信的原则，不得为获取不正当的利益，而损害买卖双方权益。（三）发现对方在业务活动中有违规、违纪、违法行为的，应及时提醒对方，情节严重的，应向对方的纪检监察部门举报。第2条卖方的责任卖方应与买方保持正常的业务交往，履行合同条款的义务，并遵守以下规定：（一）不准以任何理由向买方的相关人员赠送礼金、有价证券、贵重物品和回扣、好处费、感谢费等。（二）不准以任何理由为买方的相关人员报销应由买方或个人支付的费用。（三）不准以任何理由为买方组织有可能影响公正执行公务的宴请、健身、娱乐等高档消费活动。（四）不准以任何理由招聘或录用买方培养的专业人才和技术骨干。第3条买方的责任买方的相关人员在整个业务过程中应遵守以下规定：（一）不准向卖方索要或接受回扣、礼金、有价证券、贵重物品和好处费、感谢费等。（二）不准在卖方的单位报销任何应由买方或个人支付的费用。（三）不准参加有可能影响公正执行公务的卖方的宴请、健身、娱乐等高档消费活动。第4条违约责任（一）买方的相关人员有违反本责任书规定行为的，卖方有义务举报，买方充分保障卖方的相关业务和利益不受损害。对买方中的违法违纪者，一旦发现并经查证，买方将依据有关法律法规给予严肃查处。（二）卖方的相关人员有违反本责任书规定行为的，买方有义务举报，卖方应充分保障买方的相关业务和利益不受损害。对违法违纪的卖方，一旦发现并经查证，买方有权无条件拒付货款，并单方面解除买卖合同，今后不准列入买方的业务联系范围。第五条本责任书作为买卖双方业务合同的附件，与该业务合同具有同等法律效力，经买卖双方签署后立即生效，有效期至该业务合同执行完毕止。第六条本责任书一式三份，卖方一份，买方两份。买方：福建东南造船有限公司卖方：授权代表：授权代表：IMPORTCONTRACTContractNo:HullNo.:SignedAt:Fuzhou,ChinaDate:seethesignatureContractNo:HullNo.:SignedAt:Fuzhou,ChinaDate:seethesignatureTheBuyers:FujianSoutheastShipbuildingCo.,LtdAddress:7#JiansheRoad,MaweiDevelopingZone,Fuzhou,Fujian,CHINAMob:+86E-mail:Theseller:SignedAt:MaweiAddress:Mob:+86E-mail:ThisContractismadebyandbetweentheBuyersandtheSellers,WherebytheBuyersagreetobuyandtheSellersagreetoselltheunder-mentionedgoodsonthetermsandconditionsstatedbelow:(1) Name of Commodity, Specifications, Country of Origin, Manufacturers, Packing terms and Shipping Marks(2)Quantity(3) Price(4) date of arriving at the destination for a new shipbuilding of vessel to be constructed at the buyer’s shipyard.Manufacturer/Country of origin: _ Remark: all the technical specification and scope of supply shall be based on the technical agreement signed between Fujian Southeast Shipbuilding Co., Ltd and , the technical agreement shall be an integral part of this import contract. Shipping Mark: Mawei, Fuzhou, China1 shipset (5) Total Value: Say CIP(CIF可选) Fujian Southeast Shipbuilding (Mawei Port Fuzhou China可选) EUR only. (6)Loadingport&Destination:FromEuropemainporttoMaweiPort,Fuzhou,ChinawithtransshipmentatHongKongonly,partialshipmentnotallowed.ThedestinationisFujianMaweiShipbuildingLtd.AndtheriskofthegoodsistransferredtothebuyeratthedestinationIfthescheduleofshipbuildingischanged,theBuyerhastherighttodemandtheSellerdelaythetimeofshipmentofthecontractCommodityontime.Thereisnoextracostforthisadjustmenttobothoftheparties.Butthedelaythetimenotexpandtohalfyear.(7)TermsofPayment:??%ofcontractpriceshouldbepaidtothesellerafterreceivingthebankrefundguaranteefromtheseller.(大设备若必须付,选用此预付条款)??%ofcontractpriceshouldbeissuedbyL/C.TheSellersmustadvisetheBuyersofthetimeexpectedreadyforshipment60daysbeforeshipmentbyemail.Uponreceiptoftheadvice,theBuyersshallissue,30daysbeforeshipment,withtheBuyers’bank,anIrrevocableLetterofCreditinfavoroftheSellerspayablebytheopeningbankagainstsightdraftaccompaniedbythedocumentsstipulatedinAppendixⅡofthiscontract..Withinworkingdayafterthecontractcomesintoeffect,thebuyerprepaysthepurchaseprice,thesellerdeliversthegoodsimmediatelyafterreceivingthebuyer\'sadvancepayment,andissuesafullVATinvoicetomailtothebuyerseparately.TheSellershallnotifythebuyerbeforedelivery,thebuyershallpayforthesellerwithinworkingdayafterreceivingthenotice,theSellershallimmediatelydeliverthegoodsafterreceivingthebuyer\'spayment,andissueafullVATinvoicetothebuyerseparately.(8)Thiscontractincorporatesthefollowingdocuments:AppendixⅠ:TechnicalAgreementAppendixⅡ:GeneralConditionsofImportContractAppendixⅢ:SELLER’SIRREVOCABLELETTEROFRUFUNDGUARANTEE(若有预付款时适用)AppendixⅣ:QualityGuaranteeforwarranty(根据需求选用)(9)Effectiveness:ThisContractshallbecomeeffectiveuponitssignaturebybothparties.TheBuyers:TheSellers:TheSellers:FujianSoutheastShipbuildingCo.,LtdSignature:Signature:AppendixⅡGeneralConditionsofImportContract1.ShippingDocumentsTofacilitatetheBuyerstocheckup,alldocumentsshouldbemadeinaversionidenticaltothatusedinthiscontract.A.Fullset(3/3)originalMasterBillofLadingcleanShippedonboardmadeouttoorderandendorsedinblank,marked“FreightPrepaid”andnotifytheBuyer.Plus1Non-NegotiableCopyMarine/OceanBillofLading.B.Invoice:indicatingcontractnumber,Shippingmarks,nameofcarryingvesselandnumberoftheLetterofCredit.C.PackingListand/orWeightMemo:indicatingcontractnumber,shippingmarks,grossandnetweightofeachpackageanddescribingthedetailedgoodsandquantitiescontainedineachparticularpackage.D.Insurancepolicyorcertificatefor110%ofinvoicevaluecoveringallrisks,indicatingintheeventoflossordamage,requestforsurveyuponarrivalofthecargoattheportofdestinationbemadebytheChinaCommodityInspectionBureauofthatport.E.CertificatesofQualityandQuantity/Weightofthecontractedgoodsissuedbythemanufacturers.F.Seller’scertificate:CertifyingthatonefullsetofdocumentshavebeensenttotheBuyerwithin10daysaftershipmentandtherelativeexpresspostalreceiptorDHLreceiptisrequired.G.Packingcertificates:Seller’scertificatecertificatingthatthewoodenpackinghasbeenstampedwiththe“IPPC”(InternationalPlantProtectionConvention)markifcargoesarepackedwithwoodmaterials.OrDeclarationofNon-woodPackingMaterialissuedbytheSellerifcargoesarenotpackedwithwoodmaterialsorpackedwithplywoodorbeaverboard.H.Bankguaranteeforwarranty:Thesellershouldissuethebankguaranteewith10%contractualamount,theexpirydateshouldbe30monthsaftertheB/Lissued,theotherrequirementofbankguaranteeshouldbeinaccordancewithclause8DI.CCCcertification:ThesellershouldsubmitthebuyerCCCcertificationforallcontractualproductionsinthecatalogueofChinacompulsoryCertificationproductionstipulated.J.CertificateofOrigin:ThesellershouldsubmitthebuyertheCertificationofOriginforallcontractualproductions,whichincludethesupportdocumentsofthisCertification. Number of copies required Document To be submittedABCDEFGHIJto the negotiating bank (original)3331111111to the Buyers by express (copy)22221111112.PackingAlltheEQUIPMENT,accessoriesandcomponentssuppliedbytheSellershallbepackedsuitableforlongdistanceoceantransportationandtochangeofclimate,wellprotectedagainstmoisture,shocksandroughhandling.TheSellershallbeliableforanydamageofthecommodityandexpensesincurredonaccountofimproperpackingandrustattributabletoinadequateorimproperprotectivemeasurestakenbytheSellerinregardtothepacking.IftheSellerusewoodenmaterialtocarry,pack,level,supportorstrengthenthecommodity,thosewoodenmaterialshouldbeheattreated(HT)ormethanebrominefumigated(MB)byacompanyapprovedbytheSeller’snationalorlocalPlantQuarantineAuthorityandstampedwithstandardIPPCmarkingsspeciallyapprovedbyPlantQuarantineAuthority.Requirementsonthemarkingsareasfollows:A.StandardMarkingSample：PPCXX-000YYIPPC--Abbreviationof《InternationalPlantProtectConvention》；XX--CountryCodeaccordingtoISO;000--CodeofwoodenpackingmanufacturingcompanyapprovedbytheSeller’snationalorlocalPlantQuarantineAuthority;YY--Quarantinepeststreatmentmethods,forexample,MBmeansmethanebrominefumigated,HTmeansheattreated.B.TheSeller’snationalorlocalPlantQuarantineAuthorityorwoodenpackingmanufacturingcompanymayaddotherinformationifnecessary,forexample,DBmeansdiscardingbark.C.Markingsshouldbelegible,permanentandnottransferable;placedinavisiblelocation,preferablyonatleasttwooppositesidesofthearticlebeingcertified.D.Redororangemarkingsshouldbeavoided.3.TermsofShipmentTheSellershallundertaketoshipthecontractedgoodsfromtheportofloadingtotheportofdestinationonadirectliner,iftransshipmentisnecessary,theB/LshouldbeThroughB/L.ThecontractedgoodsshallnotbecarriedbyavesselflyingtheflagofthecountrieswhichtheBuyercannotaccept.4.AdviceofshipmentandtransshipmentTheSellershall,uponcompletionofloading,advisetheBuyerbyfax/emailofthecontractnumber,nameofcommodity,numberofpackages,grossandnetweights,invoicevalue,nameofvesselandloadingdatewithin2workingdays,Iftransshipmentisnecessary,theSellershouldinformtheBuyerbyfax/emailofthenameandvoyagenumberofsecondfeedervesselassoonastransshipmentiseffected.ThedateoftheBillofladingshallbeconsideredtheactualdateofshipmentofthecommodities5.InsuranceTobeeffectedbytheSellerfor110%ofgoodsvalueagainstAllRisksasperP.I.C.CDated2009,whichcoversoverfromthewarehouseofthemanufacturertothewarehouseofthebyer.Ifanyaccidenthappenstoanygoodsbeforetheirarrivalatthedestination,Claimsifanycoveredbytheinsurance,theSellershoulddispatchthegoodsunderthiscontractagainortakeothermeasuresaccordingtotherequirementsoftheBuyertoinsurenottoaffecttheproductionoftheBuyer’sShipyardandtheBuyershouldtransfertherightofclaimandprovidethenecessaryclaimdocumentstotheSeller.6.InspectionA.Forcommoditiestobeimported,afterarrivalofthecommoditiesattheportofdestinationand/orthesite,theBuyershallinspectthecommoditiesinrespecttotheinternalandoutwardquality,specification,quantity/weight.Ifdiscrepanciesarefoundregardingqualityorspecificationorquantity,theBuyershallhavetherighttoclaimagainsttheSellerwithintheguaranteeperiod.B.Ifthequalityandspecificationofthecommoditiesarenotinconformitywiththecontract,orifthecommoditiesareprovendefectivewithintheguaranteeperiodstipulatedinclause8.foranyreasonincludinglatentdefectsortheuseofunsuitablematerial,theBuyershallhavetherightarrangeforathirdsurveytobecarriedoutandtoclaimagainsttheSelleronthestrengthoftheinspectioncertificate.C.Accordingto“MeasuresforWoodenPackagingMaterialofEntryCargoesQuarantineSupervisionandManagement”issuedbyChinaEntry-ExitInspectionandQuarantineBureau,theEntry-ExitInspectionandQuarantineBureauwillcheckthepackingmaterialsofentrycargoesatrandom,ifthecargoesarepackedwithwoodenmaterials,buttheSellerdeclarethepackagingtonon-woodpackingmaterial,orthewoodenmaterialsarenotstampedwithIPPCmarkings,orthemarkingsarenon-standard,orlivepestsarefound,theBuyershallberequestedtoeliminatethepestsinsidethewoodenpackingmaterialanddestroythemproperlyorreturnthewoodenpackingmaterialtogetherwiththeentrycargoesandacceptthepunishmentfromEntry-ExitInspectionandQuarantineBureau.Inthiscase,theSellershallcompensatetheBuyerforallcostandpenaltyincurredduetoabovesaidreasons.7.ClaimsIncasetheSellerisliableforthediscrepanciesandaclaimislodgedbytheBuyerwithinthetimelimitofinspection,erection,commission,acceptancetestandqualityguaranteeperiodasstipulatedinclause8orelsewhereinthecontract,theSellershallsettletheclaimwiththeagreementoftheBuyerinoneoracombinationofthefollowingways.A.TheSelleragreestotherejectionoftheCommoditiesandrefundstotheBuyerthevalueoftheCommoditiesrejectedinthesamecurrencyasspecifiedintheContractandbearsthelossesandexpensesincurredincludinginterest,accruedbankingcharges,freightandinsurancepremium,inspectioncharges,storage,stevedorechargeandothernecessaryexpensesrequiredforthecustodyandprotectionoftherejectedCommodities.B.DevaluetheCommoditiesaccordingtothedegreeofinferiority,extendofdamageandamountoflossessufferedbytheBuyer,asagreedbetweentheBuyerandtheSeller.C.ReplacethedefectiveCommoditieswithnewparts,componentsand/orequipmentwhichconformtothespecifications,qualityandperformanceasspecifiedintheContract,and/orrepairthedefectiveCommoditiesattheSeller’sexpensesandrisksandbearalldirectlyrelatedexpensessustainedbytheBuyer.TheSellershallatthesametimeguaranteethequalityofthereplacedCommoditiesforafurthercorrespondingperiodaccordingtoClause8.8.WarrantyA.TheSellerwarrantsthedesign,materialsandworkmanshipoftheEQUIPMENT,accessoriesandcomponentssuppliedbytheSellerandthattheyarebrandnewandunused,andcomplywithallrespectswiththeTechnicalAgreement(AppendixI)stipulatedintheCONTRACT.Duringtheguaranteeperiod,Ifthefailureorbreakdownoccurduetosellerequipmentdesign,material,workmanship,accessoriesandcomponents.Thesellershouldberesolvedthefailureorbreakdownbyfree.B.Thewarrantyperiodbeginsatthevesseldeliveryandshallbe12monthscountingfromthedateonwhichtheVesselisacceptedbytheship-owner.However,anyreplacementsorrepairswhichareprovidedbytheSellerwithinguaranteeperiodshallbeguaranteedforafurthersix(6)monthsstartingfromthecompletionoftherelevantreplacementsorrepairs.C.Duringtheguaranteeperiod,shouldanyfailureorbreakdownoccur,theBuyershallimmediatelynotifytheSellerthedetailsofthefailureorbreakdown.TheSellershallreplyintimeandshallwithin48hoursafterhisreceiptofthenoticeassignhistechnician(s)tothesitetoeliminatethedefect(s).shouldtheSellerfailtoreplyorsendhistechnicianswithinthreedays,theBuyershallbeatlibertytoeliminatethedefect(s)byhimselfortheownerofthevesselattheSeller’sexpenseandtheSellershallberesponsibleforanyproblems.D.Thesellershouldissuethebankguaranteeforthewarrantyofcontractualequipmentwhenthecommoditydelivery,theguaranteeamountshouldbe10%contractualamount,Theguaranteeperiodwillbe12monthsaccountingfromthedateonwhichtheVesselisacceptedbytheship-owner.Theguaranteeshouldclearlyrecordthatthesellershouldbechargeofthecostwhenwarrantyhappensinwarrantyperiod.Thebankname,address,phoneNo,faxNo.e-mailaddressshouldbeclearlyrecordedintheguarantee.Thebuyeronlysubmitthewarrantyinvoicetothebank,andgetbackthewarrantyfeefrombankwhenwarrantyishappening9.ForceMajeureA.IfeitherofthepartiestotheContractispreventedfromexecutingtheContractbycaseofForceMajeureaswar,serious,typhoonandearthquake,etc.,thetimeforexecutionofthecontractshallbeextendedbyaperiodequaltotheeffectofthosecauses.AneventofaForceMajeuremeanstheeventthatthepartiescouldnotforeseeatthetimeofconclusionoftheContractanditsoccurrenceandconsequencescannotbeavoidedandcannotbeovercome.B.IncaseofForceMajeure,theSellershallnotbeheldresponsiblefordelayindeliveryornon-deliveryofthegoodsbutshallnotifyimmediatelytheBuyerbyfaxoremailanddelivertotheBuyerbyregisteredmailacertificateissuedbygovernmentauthoritiesofChamberofCommerceasevidencethereof.IftheshipmentisdelayedoveronemonthastheconsequenceofthesaidForceMajeure,theBuyershallhavetherighttocancelthiscontract.TheSeller’sinabilityinobtainingexportlicenseshallnotbeconsideredasForceMajeure.10.DelayeddeliveryandliquidateddamagesA.IftheSelleranticipatesthatwillbeunabletodeliveryanycontractualproduction(includingbutnotlimitedtocommodity，drawingorcertificates)onorbeforedeliverytimeintheContract,theSellershalltakealleffectivemeasurestoshortenthedelayimmediatelyandactively.B.IfdeliveryofthecommodityisdelayedduetotheSeller’sdefault,theSellershallpayasum,asliquidateddamageforsuchdelay,atarateof1%ofcontractpriceforeachday.TheBuyershalldeductsuchliquidateddamagesfromthecontractprice.IntheeventthattheSellerfailstomakedeliverywithin30daysafterthecontractdeliverydatespecifiedintheContract,theBuyershallhavetherighttoterminatetheContract,andallliabilitiesandcostsarisingtherefromshallbebornebytheSeller,suchas-butnotlimitedto-commercialoreconomiclosses,lossofproduction,lossofuse,lossofrevenue,lossofprofit,delayandbusinessinterruptionandothersimilarcausesorlosses,whetherdirectorindirect.C.ThesellershouldsupplythecompletedApprovaldrawingaspertheTechnicalagreementrequireddate,andsupplytheenoughquantityoffinaldrawingandcertificateswithin30daysafterthegoodsarrived,TheQuantityshouldbeinaccordancewiththetechnicalagreement;howeverincaseofanyinconsistencybetweentheimportcontractandtechnicalagreementaboutthedrawingandcertificates,thetechnicalagreementindateshallprevail.iftheSellerfailstodeliverytotheBuyersontime,liquidateddamagesshallbechargedattherateof1﹪ofthetotalvalueofcontractpriceforeachday.TheBuyershallentitletodeductsuchliquidateddamagesfromthecontractprice,andallliabilitiesandcostsarisingtherefromshallbebornebytheSeller,suchas-butnotlimitedto-commercialoreconomiclosses,lossofproduction,lossofuse,lossofrevenue,lossofprofit,delayandbusinessinterruptionandothersimilarcausesorlosses,whetherdirectorindirect.11.TERMINATIONFORBREACHOFCONTRACTTheBuyermay,withoutprejudicetoanyotherremedyforbreachofContract,bywrittennoticeofdefaultsenttotheSeller,terminatethisContractinwholeorinpart.IftheSellerfailstodeliveranyoralltheCommoditieswithinthetimeperiod(s)specifiedintheContract;oranyextensionthereofgrantedbytheBuyer;orfailstoperformanyotherobligationsundertheContract;andineitheroftheabovecircumstances,doesnotcureitsfailurewithinaperiodof15daysafterreceiptofthedefaultnoticefromtheBuyer.12.TERMINATIONFORINSOLVENCYTheBuyermayatanytimeterminatetheContract,bygivingwrittennoticetotheSeller,withoutcompensationtotheSeller,iftheSellerbecomesbankruptorotherwiseinsolvent.AndsuchterminationwillnotprejudiceoraffectanyrightofactionorremedywhichhasaccruedorwillaccruethereaftertotheSeller.13.PATENTRIGHTSTheSellershallindemnifytheBuyeragainstallthethirdpartyclaimsofinfringementofpatent,trademarkorindustrialdesignrightsarisingfromuseoftheCommodities,ServiceoranypartthereofinPRC.Incaseanythirdpartybringsachargeofinfringement,theSellershalltakeupthematterwiththethirdpartyandbearalllegalandfinancialresponsibilities,whichmayarise.14.ArbitrationAlldisputesinconnectionwiththisContractortheexecutionthereofshallbesettledbyfriendlynegotiation.Ifnosettlementcanbereached,thecaseindisputeshallthenbesubmittedforarbitrationtoHongKongInternationalArbitrationCenter,HKIAC,HOKONG,inaccordancewithitsrulesofarbitration.ThedecisionmadebytheCommissionshallbeacceptedasfinalandbindinguponbothparties.TheBritishlawshouldbeapplied.ThefeesforarbitrationshallbebornebythelosingpartyunlessotherwiseawardedbytheCommission.(仲裁法律为香港的适用这一条,根据实际情况选用)AlldisputesinconnectionwiththisContractortheexecutionthereofshallbesettledbyfriendlynegotiation.Ifnosettlementcanbereached,thecaseindisputeshallthenbesubmittedforarbitrationtotheChinaInternationalEconomicandTradeArbitrationCommission,BeijingCommission,inaccordancewithitsrulesofarbitration.ThedecisionmadebytheCommissionshallbeacceptedasfinalandbindinguponbothparties.TheChineselawshouldbeapplied.ThefeesforarbitrationshallbebornebythelosingpartyunlessotherwiseawardedbytheCommission.(仲裁法律为中国的适用这一条,根据实际情况选用)15.safetyproductionclausesThesellershouldarrangetheserviceengineertothebuyerinaccordancewiththecontractrequirement.Theengineershoulddresstheworkingclothes,shoes,helmet,safetybeltetcforthesafetyofthework.Theserviceshouldhavetheenoughqualificationtomakesuretheworkcompletedfully.Thesellerhavetheobligationtoinformtheengineerfullfollowingthebuyer’srulesandregulations.Theengineerarriveatthebuyer,safetyeducationisrequired,theengineershouldread‘safetynotice’,safetyeducationvideocarefully,thensignthesafetyeducationrecord.Ifanyaboveeducationisrefusedbytheengineer,thebuyerwon’tallowedtheengineertowork,alllosseswillbeliabilityofbytheseller.Theengineershouldobeythebuyer’ssafetymanagement,Iftheengineerrefusethesafetyeducationorbreakthebuyer’srulesandregulations,thebuyerhavetherighttorequireanewengineertoinsteadof,Ifthissituationbringsomelossesforthebuyer,itwillbeliabilityofbytheseller.Theselleristhefirstpersonresponsiblefortheengineer.Andpurchasetherelevantinsuranceforthem.ItshouldsupplytheenoughsafetyeducationtomakesuretheycouldobeyChinesesafetyproductionlawandbuyer’srulesandregulationsetc.IfsomeaccidentishappenedduetoTheengineerbreakthebuyer’srulesandregulations,wrongoperationetc.Andresultoftheengineerhurt,thesellershallberesponsibleforit.thebuyerwon’tbeliabilityofit.16.Commissioningandseatrials,totaldays:days/trips.A.Thebuyershallberesponsiblefortheinstallationofthegoods.Theinstallationshallperformedbythebuyerinaccordancewiththeguidelinesandproceduresoftheseller.Thesellershallbeinchargewithresponsiblefortheinstallationofthegoods,andshallprovidethebuyerwithguidelinesorproceduresforitsuse.B.Followinginstallation,thegoodsshallbecheckedandstartedbytheselleruntilthegoodscanbeusednormally.(“commissioning”)Ifnot,theSellershallberesponsibletore-performtheCommissioning.C.Thesellershallsupplysuitablelabor,theworkclothes,shoes,safetyhelmet,toolsandmaterialsduringthecommissioning/seatrialsperiod.Thebuyermayprovidenecessaryassistancetotheseller.D.Thebuyershallnotifythesellerofthecommissioning/seatrialsdateatleast7daysprior.Thesellershallarrangetheserviceengineertoyardstrictlyinaccordancewiththebuyer\'snotificationontimeaccordingly.Shouldthesellerfailtosendaqualifiedserviceengineerforcommissioning/seatrialsinatimelymannerwithouttheapprovalofthebuyer,thesellershallpaytheliquidationdamagesofUSD1000perdaytothebuyerforthedelay.Andthebuyerreservestherighttoclaimfurtherlossesresultingfromthebreach.Thesellershalldesignateexperiencedandcompetentserviceengineer(s)toprovidethecommissioning/seatrialsserviceonsitewithinthebuyer\'sworkingtimeonworkingdays,unlessthebuyerrequiresotherwise.Incase,however,iftheserviceengineerisincompetentorinexperiencedthentheworkingtimeshallbeprolonged,thedaysbeyondthatperiodshallbefreeofchargeuntilsuchworkissuccessfullycompleted.Alternatively,ifthesellerwantstoplacethetraineeinthebuyer\'sprogram,thetrainee\'stimecannotbechargedtothebuyer.E.Thesellerwillsupplyatotalof？man-daysfreecommissioning/seatrialsforthevessel.Theservicechargesbeyondtheperiodofservicegiveninthesaidcontractshallbeexecutedasfollows:Commissioning(8hoursperday)inshipyardUSD？perman-day.Seatrial(16hoursperday)USD？perman-day.F.Ifanymissingordamagedpartshappenduetothesellerandcausesomeservicetimebewastedduringthecommissioningperiod,thattimeshallnotbeincludedinthecontractualservicetime.Iftheengineerworkingtimeislessthan8hoursonboard(excludingtraveltime),thesellershouldcomplement,ordeductitinthefinalsettlement.G.Ifthefreeservicetimeofthecontractisnotfullyexhausted,theselleragreestotransfertheremainingtimetothesistervesselcontractedbythesellerandthebuyer.H.Duringtheserviceperiod,theserviceengineershallabidebythebuyer\'ssafetyproductionrulesandregulationsapplicabletotheworksiteand/orHSElaws.Theengineershouldobservethebuyerworktime,regulation;lateorleaveearlystatusisn\'tallowed.whentheprojectscheduleisurgent,theengineercooperatesandassistonthebuyerfinishtheurgentjob.Thesecurityoftheserviceengineeratthebuyer\'splaceshallbetheresponsibilityoftheseller.17.SpecialClauseA.Ifanyadditionalcostsofpartialshipmentormissingpartialshipmentcausedbytheseller,includingthecustomscharge,freight,taxes,demurragechargeetc.Shouldbechargedtotheseller’saccount.OrthesellerarrangesallmissingpartstothebuyerbyDDPFujianmaweishipbuildingltd.B.Iftheshipbuildingcontracthasbeencancelledbytheshipowner,theBuyershastherighttoterminatethiscontractaftercompensationtheseller’slosseswhichamountshallnotexceed5percentoftheimportcontractpriceinanyevent.C.ThecommercialcustomsnotdescribedintheContractshallbeinaccordancewiththetermsandconditionsofINCOTERMS2010.D.Thesellershallmakesureallgoodsdonotcontainasbestosmaterial,andprovidethe\"noasbestosdeclaration\"(accordingtothebuyer’ssample)andthequalifiedthirdpartyinspectionreportofnon-asbestosmaterialsuchassupportingdocumentstothebuyerin3workingdayswhenthegoodsarriveatthedestination.Iftheasbestosmaterialisfoundingoodsbythebuyer,Thesellershouldbeliabilityofallresponsibilitiesandlosses,whichshouldinclude,butnotlimitedtothecostandlossesforwholevesselinspectionofnoasbestosmaterial.Iftheasbestosisfoundafterthevesseldelivery,thesellershallbeliabilityofalllossescausedbytheasbestos,anditisnotlimitedbythewarrantyperiodandotherslossandliquidatedamagesclausesstipulatedinthecontract.E.Thesellerwillbechargeoftheexport&importclearanceprocedure,thebuyerwillassistonsupplyingtheimportdutyfreeregistertotheseller.Thesellerwillinformthebuyernecessaryinformation,documentsat60daysinadvancebeforeequipmentdelivery,forexample,equipmentname,HScodeetc.thebuyerwillpreparetheimportdutyfreeregisteraccordingly.(保税区发货时选用此条款)F.ThesellershouldobserveChineselaw,Chinesecustomsregulation.exceptforthecontractualgoods,anysomethingofendangeringnationalsecurityisn’tallowed,forexample,thenarcoticdrugs,weaponsetc.IfThesellerbreaktheChineselawandChinesecustomsregulation.Alloftheliabilityshouldbebornebytheseller.卖方必须遵守中国法律和海关的相关规章制度，除合同项下货物以外，不得随货夹带任何危害国家安全的东西，例如，毒品，武器等等；如果卖方违返了上述规定，卖方应承担所有的责任。G.Regardingtonegotiationwiththebuyerandtheseller,AllpartneragreetofollowtherequirementofAuthorizedEconomicOperator(hereafterrefertoas“AEO”)forbusinesspartnerssafety.andwillmanageandimproveallproceduresinbusinessactivity,whichincludethesafeforworkshop,staff,cargo,transportmachine,entrancemanagement,riskmanagementetc.根据买卖双方友好协商，一致同意双方将遵照海关AEO认证的标准化流程对贸易安全进行管理和完善。其中包括：场所安全、人员安全、货物安全、运输工具安全、危机管理、门禁管理等内容H.AllcontractualproductionsshouldbefullymeetingthecatalogueofChinacompulsoryCertificationproductionstipulated.AndsubmittheCCCcertificationtothebuyer.Ifthesellercan’tsubmittheCCCCertification,andresultofthebuyer’scustomclearancefail,thesellershouldfindthesolutiontomeettheCCCcertificationorreplacetheadequateproductiontothebuyerbyfree.Ifanylosshappens,TheSellershouldbeliabilityofit.TheBuyers:TheSellers:FujianSoutheastShipbuildingCo.,Ltd.Signature:Signature:AppendixⅢSELLER’SIRREVOCABLELETTEROFRUFUNDGUARANTEETo:Date:DearSirs,IrrevocableLetterofGuaranteeNo.Whereas**(hereinaftercalledthe\"SELLER\")and****,havingitsregisteredofficeat****and***(hereinaftercalled\"You”),concludedon****aContractNo.****withaddendaasthesamemaybefurtheramendedand/orsupplemented(hereinaftercalledthe\"Contract\")thattheSELLERwouldselltoyouone(1)****(hereinaftercalledthe\"Commodity\")tobedesignatedasHullNo.****.InconsiderationofyouagreeingtopaytheSELLERthecommodityprice,we,****,guaranteerepaymenttoyoubytheSELLERofanamountuptobutnotexceedingUnitedStatesDollars****only(USD****)NOWTHEREFORE，we(nameofguarantor)attherequestoftheBUYERherebyirrevocablyissuethisRefundGuaranteeandundertaketopayyou,uponreceiptofyourwrittendemandstatingthattheSELLERhasfailedtoperformhisobligationsasstipulatedintheContract,thesumorsumsnotexceedingtheabove-mentionedamount.Ourliabilityhereundershallbelimitedto(theamountofguarantee).ThisguaranteeshallbecomeeffectiveonthedatetheSELLERreceivestheaforesaidadvancepaymentfromyouandshallremainvaliduntilthedateofdeliveryandacceptanceoftheCommodity(theexpirydateofthisguarantee).TheguaranteedamountshallbeautomaticallyandproportionallyreducedbytheamountwhichtheSELLERhasalreadyrepaidtoyou.Bestregards【】Bank(根据实际情况选用)AppendixⅣQualityGuaranteeForWarrantyTo:Gentlemen:1.InconsiderationofFujianMaweiShipbuildingLtd..(hereinaftercalledthe“BUYER”)enteringintoacontract****(hereinaftercalledthe“CONTRACT”)with*Ltd.(astheSELLER)forthesaleofone****(hereinaftercalledthe“Commodity”)we(BANK)herebyirrevocablyandunconditionallyundertaketoholdatyourdisposalthesumofEUR51,500whichweshallpayyouwithoutanyreferenceto,andinspiteofanycontestationbytheSELLERimmediatelyonyourdemandbeingmadetousinwritingwiththefollowingdocuments:a:Originalorcopyinvoiceofthethirdpartywhoeffectedsuchrepairsstatingtheexactamountdemandandthepartsrepaired.b.Seller’sconfirmationontheclaimontheequipment/machinerydefect2.Thisguaranteeshallbevalidfromthedateofissueuntil30monthsfromthedateofdeliveryandacceptanceoftheCommoditythatisuntil……………….3.Anyclaimmustbereceivedbyusinwritingonorbeforetheexpiryofvaliditydate,uponexpirytheguaranteeshallbenullandvoidwithoutnecessityofbeingreturnedtous.ForandonbehalfofBank(signedandstampedbythebank)By:…………………………..Name:…………………………..Title:…………………………..This……………..dayof………………TecwayInternational(Marine)Limited福建东南造船有限公司TANo.：FSMW651-TA-E11-01tojfanSuthhShtpbmleinga.td技术协议书TECHNICALAGREEMENT船号HULLNo.：MW651-1/2船名SHIPNAME：37m多用途支持船37mMULTI-PURPOSESUPPORTVESSEL船级社+入级标志CLASS+NOTATION:BVIBHULL.MACHTUGANCHORHANDLING.UNRESTRICTEDNAVIGATIONAUT-UMS.INWATERSURVEYCLEANSHIPGREENPASSPORTEUCYBERRESILIENT挂旗(船籍）FLAG(REGISTRY）塞浦路斯斤CYPRUS项目：汽雾笛AirhomSUBJECT型号：见协议MODELSeedetailinformationintheTA制造厂/制造国：WahJetXijiangAirSirenMachineCo.Ltd/ChinaMANUFACTURER/COUNTRY:代理商：AGENCY数量QUANTITY:1（套/船SET/SHIP）湖华买方BUYER:福建东南造船有限公司签字：FujianSoutheastShipbuildingCo.,Ltd.design@maweiship.comlinzhong@maweiship.comApprovedby05.11.11江培广领设计方DESIGNER:福建省福船海洋工程技术研究院有限公司签字：FOETRISignedby:2025.11.11卖方SELLER:WahJetXiangAirSirenMachineCo.Ltd签字：权种联系人CP：张权科Signedby:电话TEL13927124839邮箱E-MAIL:xijiang@gdxihang.com1/22福建东南造船有限公司TANo.：FSMW651-TA-E11-011uiaaSaathShfphmlleinge.t1.概述GENERAL1）设备和材料应符合船舶建造合同签订时以及签订前生效的最新BV船级社规范和挂旗国当局要求，包括其附录及修正案。EquipmentandmaterialshallcomplywihthelatestrulesandregulationsofclassificationsocietyBVandflagstateincl.annexesandamendments，thatcomeintoeffectiveatandbeforethetimewhenthevesselBuildingContractissigned2）车间台试前30天，卖方应通知买方和船东参加测试并提交相关的检验或测试项目。30dayspriortoshoptest,SellershouldinformBuyerandOwnertoattendthetestandatthesametimesubmittheinspection/testitemsinformationtothem3）本协议在设备订货合同生效时同时生效。ThisAgreementshallbeeffectiveonthedatewhentheContracthasbeendulyexecuted4制造厂商应保证设备符合买方的确认图纸（包括修改注解）。加工过程中若有必须的修改，制造厂商应立即联系并获得买方同意，并且提交修改标记和注解说明。TheMakershallguaranteethattheequipmenttheysuppliedshallcomplywiththeworkingdrawingconfirmedbyBuyer（includingmodificationaccordingtocomments）.IncaseanymodificationisnecessaryduringtheprocessofmanufacturetheMakershallimmediatelycontactandobtainconfirmationfromtheBuyerandsendtheBuyerthemarkingofmodificationsandtheexplanations5所有买方认可的修正，卖方应在认可注解和认可工作图的封面上做说明，并且应有明确标识。重要性能的更改应由买方认可。AllrevisionsagreedbytheBuyershallbenotedonfrontcoveroftheconfirmationandworkingdrawingbytheSeller,andshallbemarkedclearlyinthesedrawings.TherevisiononimportantperformanceshallbeagreedbytheBuyer6制造厂商应在5天内，确认买方的认可注解或解释自己的未认可原因。MakersshallgivereplyaboutBuyersconirmationcommentsorgiveexplanationforfailureofitwithinsdays7）完工图应与提供的设备相符。尽可能的使用能长期保存的印刷图纸。Thefinaldrawingistobeinconformitywiththeprovidedequipments.Forhardcopiesprintsasfaraspossibleshallusepaperthatsuitableforlong-termconservation.8）每套设备应在明显的位置装有铭牌，包括设备名称，型号和制造商等等。设备及其控制箱互为备用的，厂家制作铭牌时应标明1号、2号，加以区分；EachsetofequipmentistobefittedwithanameplateinnotableplacewithequipmentnamemodelcodeandtheMarkersname,etc.Equipmentandcontrolboxeswhicharestandbyforeachothershouldbemarkednumberone,numbertwoonnameplatesfordistinguishing.9设备的维护，在交付前由制造商承担。MaintenanceistobedonebytheMakerbeforedeliveryofequipment10)所有设备如有必要制造厂商应提供特殊的安装工具等，所有需满足船上设备和机械大修及安装需要的特殊工具（根据厂商标准）须提供到船。Specialinstallationtoolsetc.shouldbedeliveredbyMakerifnecessary.Allspecialtoolsnecessaryforoverhaulingandassemblingofanyoftheequipmentandmachineryonboardoftheship（asperMakersstandard）aretobedeliveredonboardoftheship12/22福建东南造船有限公司TANo.：FSMW651-TA-E11-01jiaSaathshtphmlleingce.d11电机证书的配备根据船级社的要求。CertificatesofE-motoristobeprovidedaccordingtotherequirementofClass所有电动机均应符合以下规格：·船用型、高能效型●鼠笼式预装滚珠轴承除非另有说明，否则为全封闭式（TEFC）自通风室内的防护等级为IP44，室外的防护等级为IP66“F”级绝缘外壳接地连接具有变频控制功能的电动机应配备独立的轴承接地和轴接地。电动机额定值、机座尺寸、效率等级、扭矩/转速曲线应符合IEC规范（参见本技术协议第6.3节）。在电压低于15%、频率低于5%的情况下，电动机应能正常启动。S1型电动机应至少每小时能进行6次直接启动。附加说明：·功率大于1千瓦：电机为三相3x400伏交流电类型。功率低于1千瓦时可为单相2x230伏交流电。功率大于7.5千瓦：电机配备绝缘等级H级和温升F级，并配有烘潮加热器且加热器在启动电机时应自动关闭。功率大于22千瓦：每相绕组中应配备一个（1）热敏电阻器。功率大于75千瓦：每相绕组中应配备2个PT100（而非热敏电阻器）。功率大于132千瓦：电缆传输应采用MCT型的电缆贯穿件（而非电缆填料函），以便在不拆MCT块的情况下单独拆除电缆。外部甲板上的无冷却装置的电动机应满足最低和最高环境温度要求。推进器电机将由AFE变频器控制，以限制谐波失真。Allelectricmotorsshalladheretothefollowingspecification:Marinetype,higheficiencytypeSquirrelcagerotorPreloadedballbearingsTEFCunlessstatedotherwiseSelf-ventilatedProtectionIP44indoor,IP66onoutdoorClass“F”insulationEarthconnectiononthehousingElectricmotorswithvariablefrequencycontrolshallhaveisolatedbearingsandshaftearthing.Ratings,framesizes,efficiencyclass,torque/speedcurvesinaccordancetoIECregulations（see6.3ofthisTA).Atanundervoltageof15%andanunderfrequencyof5%electricmotorsshouldstartwithoutanyproblem.Slmotorsshallbesuitableforatleast6DOLstartperhour维的3/22福建东南造船有限公司TANo.：FSMW651-TA-E11-011ujfanSauthhtsnfpnmilaingee.tAdditionalspecifications:Motor>1kW:motoris3-phasetype3x400VAC.Below1kWmaybesinglephase2x230VACMotor>7.5kW:motorprovidewithinsulationclassHandtemperatureriseFrating，andstand-stillheatingelement,andtheheaterofmotorshallbeswitchedoffautomaticallywhenstartingthemotorMotor>22kW:motorsshallbeprovidedwithone（1）PTCineachwinding.Motor75kW:motorsshallbeprovidedwith2xPT100（insteadofPTC）ineachwinding.Motor>132kW:MCTtypeofcabletransit（insteadofcableglands）onseparateremovableplatetoallowremovalofthecableswithoutopeningtheMCTblocksElectricmotorsonoutsidedeckswithoutcoolingprovisionswillbedimensionedforlowestandhighestambienttemperatureBowthrustermotorwillbecontrolledbyanAFEfrequencyconverterlimitingtheharmonicdistortion起动器：功率0.5kW及以上的电动机须按规范要求配备起动器。原则上，用于必要用户的电动机起动器须集成到MCC控制板，且在电动机附近配备一个就地按钮盒，同时必要用户的起动器须配备电流表和计时器。单个起动器可根据需要应用于其他电机。所有的开孔和门边缘按规范要求须适当用垫圈密封以保证IP22或IP44或IP56防护等级。32kW以下的电动机应为“直接在线”起动，32kW（含）以上的电动机应为‘Y-D'（星三角）起动。10kw以上且由应急配电板供电的电动机应为‘Y-D'（星三角）起动或为其它合适的降级起动方式。StartersThestartertobeprovidedformotorsrating0.5kWandaboveinaccordancewithrulesrequirement.Ingeneral,themotorstartersforessentialconsumerstobeintegratedintotheMCCpanels，withalocalpush-buttonboxlocatednearthemotor，andtheessentialconsumersstartertobefittedwithanammeterandhourcounter.Theindividualstartersmaybeappliedforothermotorsasrequired.AllcutoutsanddooredgesshallbeproperlysealedwithgasketstoensureIP22orIP44orIP56protectionasrequiredbytherules.Motorsbelow32kWratingtobe“Directonline”started,andmotorsrated32kW（inclusive）andabovetobestartedbymeansofY-D'Star-Delta）starter.Themotorsgreaterthan10kWandpoweredbytheESBtobeof‘Y-D'startingorothersuitablestep-downstartingmethods12）卖方必须将设备的外形尺寸和重量附在本技术协议中。认可图、工作图必须注明每一部件的重量和总重量，认可图显示的重量、工作图显示的重量、实际来货的重量相较与技术协议显示的重量有变化的，卖方需要相应记录并通知买方。实际来货的重量与技术协议显示的重量的偏差须在3%之内。TheoutlinedrawingandweightoftheequipmentsmustbeattachedtothisTechnicalAgreementbytheSeller.Approvalandworkingdrawingmustindicatethetotalweightandweightofeachmainpart,incaseofweightindicatedonapprovaldrawing，weightindicatedonworkingdrawing，weightofactualdeliveredequipmenthasanydeviationfromweightindicatedonTechnicalAgreement，theSellermustaccordinglyrecordandinformtheBuyer证维4/22福建东南造船有限公司TANo.：FSMW651-TA-E11-01janSouthatsnphmlleingP.irdTheweightdeviationofactualdeliveredequipmentcomparetoweightindicatedonTechnicalAgreementshallbewithin3%.13）在可能的情况下设备或系统应标准化以尽量减少备品备件量。所有设备的备品备件工具须按照挂旗国、船级社的要求和至少壹（1）年操作的厂家推荐。特殊型式泵浦需有机械轴封、轴心与轮叶等备品。Wherepossibleequipmentorsystemsaretobestandardizedtokeepstoresandsparestoaminimum.Spareparts,inventoryandtooisforallequipmentaretobeprovidedaccordingtoFlagStageandClassrequirementsandMakersrecommendationforoperationperiodminimumone（1）yearThesparepartsforspecialtypepumpsshouldincludingmechanicalshaftseals,impellers,shaftsandsoon14）主要机械设备按厂家的专门品牌；除厂家专门品牌颜色外，电气设备的颜色标准为：MunsellcodeN0.7.5BG7/2(浅灰色）。应急和报警设备的颜色为：Munsellcode5R4/13（红色)。电气设备内部颜色以厂家标准颜色为准。特殊设备，如航行设备、无线电设备、内部通信设备等，以厂家标准颜色为准。所有电气控制箱的颜色尽可能是MunsellcodeN0.7.5BG7/2浅灰色）。TofollowtheMakertrademarkcolorforallmajormachinery.ExceptMakerstrademarkscolor，thepaintingofelectricequipments'colorshouldbeMunsellcodeN0.7.5BG712lightgrey).TheemergencyandalarmdevicewithMunsellcode5R4/13Red）InteriormetalsurfacesofelectricequipmentshouldbepaintedwithMakersstandardcolors.Thespecialequipment，suchasnauticalequipment，radioequipment，intercommunicationcquipmentetc.shouldbepaintedwithMakersstandardcolors.AllelectriccabinetstobecolorMunsellcodeN0.7.5BG7/2（lightgrey）asfaraspossible15）厂家须提供设备无石棉证书或声明书，满足规范要求。证书或盖公章声明书原件随认可图发船厂。MakershouldsupplytheasbestosfreeCertificateortheasbestosfreestatementfortheequipmenttofulflltheClassrules.AndthecertificateorthesignofficialsealedoriginalstatementshouldbesubmittedtoShipyardwithapprovaldrawing16）厂家须根据“BVNR528,notationGREENPASSPORTEU”的要求，填写并提供“供应商的一致性声明表格--（SDoc）”和“材料声明表格--（MD）”。该声明表格随认可图发船厂。TheSellermustfillandprovideSupplierDeclarationofConformityform--（SDoc）”andMaterialDeclarationform-（MD)”accordingto“BVNR528notationGREENPASSPORTEU”Supplythedeclarationformwithapprovaldrawings17)所有设备须列出主要部件的型号和厂家（品牌）。ThemaincomponentsofallequipmentshouldlistthetypeandMaker（brand）18)所有设备的管子进、出口连接位置须便于船厂外部接管，且设备本体管子固定整齐。Allequipmentpipesinlet/outletpositionshouldbearrangedconvenientforYardpipingconnection,andpipesattachedonequipmenttobefixedproperly.19)所有设备电缆填料函进线位置须便于船厂外部接线，且设备本体电缆用扁铁或托架固定整齐。AllequipmentcableglandsinletpositionshallbearrangedconvenientforYard'scable维门5/22福建东南造船有限公司TANO.：FSMW651-TA-E11-011ujanSuutsrhsntpnmlainge.itawiring,andcablesattachedonequipmenttobefixedproperlybycabletrayorflatbar20）厂家应保证设备送审的所有BV船级社退审意见要关闭。MakermusttakeresponsibilityforclosingalltheBVClassificationSocietycommentsfordrawingswhicharesubmittedbytheMaker21）本技术协议采用中英文对照形式，若两者有矛盾，须以英文为准。ThisAgreementiswritteninChineseandEnglishlanguagesanditmustbeaccordingtoEnglishlanguageifcontradictionsoccur2.基本技术参数Basictechnicalspecification1）船舶加速度和最大纵倾斜角及横倾角按船级社和SOLAS要求。船舶、轮机系统、辅助设备，以及空调和通风系统须按以下条件执行：Ship'saccelerationandmaximumtrimandlistinaccordancewithClassRulesandSOLAS.ThedesignoftheVessel,machineryinstallation,auxiliaryequipment,andairconditioningandventilationssystemsisbasedonthefollowingconditions:内容Description温度Temp.相对湿度（最高）RH（max.）外界海水最低温度Min.ambientseawatertemperature-2℃外界海水最高温度Max.ambientseawatertemperature37℃外界大气最低温度，风速为25m/s时Min.outsideairtemperature,withwindspeedof25m/s-10℃60%外界大气最高温度Max.outsideairtemperature45℃50%高湿度时外界大气最高温度Max.outsideairtemperatureathighhumidity35℃90%冬季上建和驾驶室室内温度Winterinsideairtemperatureinaccommodationandwheelhouse22℃50%夏季上建和驾驶室室内温度Summerinsideairtemperatureinaccommodationandwheelhouse25℃50%冬季配电间或上建服务处所室内温度Winterinsideairtemperatureinswitchboardroomortechnicalspacesinaccommodationarea22℃50%夏季配电间或上建服务处所室内温度Summerinsideairtemperatureinswitchboardroomortechnicalspacesinaccommodationarea27℃50%机舱最低温度Min.engineroomtemperature10℃机舱最高温度Max.engineroomtemperature55℃封闭处所最低温度Min.temperatureinenclosedspaces5℃封闭处所最高温度Max.temperatureinenclosedspaces55℃低温冷却水最高温度Max.LT-coolingwatertemperature43℃2）证书要求（所有证书应提供1正2副及PDF电子版）Certificatesrequired（allcertificatestobedeliveredinloriginaland2copies,andalsoin缢n6/22福建东南造船有限公司61jaaSonhstphmlaigp.tdTANo.：FSMW651-TA-E11-01-功能/用途简述-Shortdescriptionoffunctionality/purpose物理接口（如网络、串口）-Physicalinterfaces（e.g.，network,serial）-系统软件（如操作系统、固件）的名称/类型-Name/typeofsystemsoftware（e.g.，operatingsystem,firmware）-系统软件的版本和补丁级别-Versionandpatchlevelofsystemsofware-支持的通信协议-Supportedcommunicationprotocols-软件组件清单（如应用软件、实用软件）-Listofsoftwarecomponents（e.g.，applicationprogram,operatingsoftware）-安装的硬件组件-Thehardwarecomponentwhereitisinstalled-品牌/制造商-Brand/manufacturer-型号/类型-Model/type-功能/用途简述-Shortdescriptionoffunctionality/purpose-软件版本-Versionofsofware3）标准Standard●材料、机器和设备总体上须按照ISO标准、IEC标准，除非另有特别同意或注明。·所有露天处所的管路须为防腐蚀的（不锈钢ANSI316L或塑料材质）一般系统管子：GB标准、公制标装液压系统管子：DIN标准、公制标准管路法兰、附件：DIN标准、公制标准，且法兰与管子应为同样材质法兰螺栓和螺母：法兰连接所用的螺栓和螺母应为六角头型。通常进行镀锌处理。在压载舱以及机器处所的地板以下区域以及船体的护舷处，应使用不锈钢（AISI316）材质的螺栓和螺母。管子固定螺栓和螺母：U型抱箍和螺母应为镀锌，但用于压载舱、燃油舱和水舱的须为不锈钢（ANSI316）。机舱管子固定须使用单螺母，但机舱地板以下的须使用双螺母；舱内DN80及以上的管子固定须使用双螺母；上建的须使用单螺母。所有的工艺须满足认可的造船质量标准，也须满足船东的要求。焊接须遵循船级社的要求。所有用于船舶建造的材料、机器和设备必须是新的且未使用过的，须满足认可的造船质量要求，并满足功能要求的，同时也需得到船东和船级社的认可。对于其它地方未提及的露天环境和潮湿区域的所有不锈钢部件，包括用于船体、舱盖、附件、设备等的不锈钢部件，其材质须为AISI316（L）或更高等级。若无法采用AISI316L）等级制品，则须选用具有抗海水腐蚀性能的其他等级不锈钢，并需经船东批准，具体要求依据申请内容和/或具体位置而定。如有需要，将进行酸洗/钝化以及焊前和焊后退火处理。牛油嘴须为平头式，DIN3404标准。用于露天处所的牛油嘴须为不锈钢ANSI316.Materials，machineryandequipmenttobegenerallyinaccordancewithISOstandardsIECStandardsulessspecificallyagreedorstatedAllweatherexposedpipingwillbecorrosionfree（stainlesssteelAISI316Lorplastic）.Pipesforcommonsystem:GBstandard,Metricstandard维n8/22福建东南造船有限公司TANo.：FSMW651-TA-E11-01tuganSaatrshpnmleing.td·Pipesforhydraulicsystem:DINstandard.Metricstandard·Pipingflanges,fittings:DINstandard,Metricstandard,andflangesandpipestobesamematerialBoltandnutsforflanges:Boltsandnutsforflangeconnectionsshallbeofhexagonalheadtype.Galvanizedingeneral.Stainlesssteel（AISI316)inballasttanksandbelowfloorplatesinmachineryspacesandforfendersonhullPipesecuringboltsandnuts:U-typeboltsandnutsshallbegalvanized.InballasttanksfueloiltanksandwatertankstheU-typeboltsandnutstobestainsteel（AISI316).Singlenutshallbeusedforallpipesupportsinengineroomexceptunderfloorplateswheredoublenutshallbeused.IntanksdoublenutforpipingDN80andabove.InaccommodationsinglenuttobeusedAllworkmanshipistobeofacceptableshipbuildingstandard，andistobetothesatisfactionoftheOwner.WeldingtocomplywithClassrequirementsAllmaterialmachineryandequipmentusedintheconstructionoftheVesselaretobenewandunused,ofacceptableshipbuildingquality,suitablefortheintendedserviceandapprovedbytheOwnerandtheClassificationSociety.Allstainlesssteelincludingfittings,whereusedinthehullhatches,fittings,equipmentetc.,inweatherexposedorwetareanotmentionedotherwise,aretobegradeAISI316(L）orbetterWhereitisnotpracticaltofitthisgradeAISI316L）anyothergradeofstainlesssteelmustbeofseawaterresistantgradeandapprovedbytheOwner，perapplicationand/orlocation.Whereapplicable，pickling/passivationandpre-andpost-weldannealingwillbeexecutedGreasenippleswillbeofflatbuttonheadtype,DIN3404.ForweatherexposedareasthesewillbeofstainlesssteelAISI316.4）尺寸单位Measuringunit:有关仪器、仪表或计量装置须满足认可的质量并满足所需的功能需求，非可腐蚀性材质且以公制单位指示。Associatedinstruments，gaugesormeteringdevicesmustbeofacceptablequality,fitfortheintendedpurpose,non-corrodibleanddelineatedinmetricunits5）铭牌/操作说明牌Nameplate/instructionplate铭牌/操作说明牌须使用英文，且使用耐腐蚀性材料（室外的铭牌及信息牌须为不锈钢材质）。Nameplate/instructionplatetobeinEnglish,andadoptnon-corrosivematerial（foroutdoorones,shallbestainlesssteel）所有设备和主要部件须带完整的永久性标识铭牌。标识须至少体现生产商名称或商标、型号、尺寸和额定参数。Allequipmentandmajorcomponentsaretocarrypermanentidentificationnameplate.Theidentificationistoshow,atminimumthemanufacturesnameortradename，modeltypesizeandrating.配电板相关的所有部件须提供铭牌，以清晰体现部件的功能和额定电流（适用之处），铭牌须按厂家标准用铆钉或螺丝固定。分电箱每一路出线须配备铭牌以体现线路、额维n9/22福建东南造船有限公司FjanSeathashfpbmllainga.dTANo.：FSMWG51-TA-E11-01定电流等信息。Allcomponentsontheswitchboardshallbeprovidedwithnameplatesclearlyindicatingthecomponentsserviceandthecurrentratings（whereapplicable），thenameplatesshallbesecuredwithrivetpinsorscrewsasmakersstandard.PowerDistributionBoardeachoutgoingcircuitshallbefittedwithanameplateindicatingthecircuitsratedamps,etc6电制Powersource:AC:400V/230V/50HzDC:24V推：按厂商要求操锚绞车：按厂商要求主要用电设备：400VAC@50Hz,3phase照明：230VAC@50Hz,1phase,均为LED型应急照明：230VACa50Hz1phase和24VDC；无内置电池航行灯：24VDCLED型助航设备：230VAC@50Hz,1phase和/或24VDC监控和报警：230VACa50Hz1phase和24VDC岸电：400VAC@50Hz,3phases通过隔离变压器Bowthrusterservices:SuppliersdiscretionAnchorwinchserviceSuppliersdiscretionPowerconsumers:400VACa50Hz3phaseLighting:230VAC@50Hz,1phase,allofLEDtypeEmergencylighting:230VAC@50Hz,1phaseand24VDC；nointernalbatteriesinthearmaturesNavigationlighting:24VDCLEDtypeNauticalequipment:230VAC@50Hz,1phaseand/or24VDCAlarm，andmonitoring:230VAC@50Hz,1phaseand24VDCShorepowersupply:400VAC@50Hz3phasesviaagalvanicseparation（transformer）7）设备本体上的传感器由厂家接至统一的接线盒或控制箱内，设备本体上由厂家预装好合适的电缆固定件如扁铁或托架。Junctionboxestobesuppliedandmountedforallsensorsonsetsifany.Andcabletraysorflatbartobeinstalledonsetsforyardscablessecuringandconnection.散供的传感器由厂家配合适的填料函（钢质或铜质），填料函大小认可图阶段确认。Loosesuppliedsensorsshouldbeprovidedwithpropercableglands,theglandsmaterialshouldbesteelorbrass,thesizeofglandstobeconfirmedbyShipyard控制箱内部接线需有明确标识。Innerconnectionofcontrolboxesshouldbeclearlabeled.设备电控箱内需配有限位卡扣。Thecontrolboxofequipmentneedsadoorstopper所有控制箱上需要带标有IP等级和电制的铭牌。AllcontrolboxshouldhavenameplatewithIPclassandPowersource配电板、变频器、推进电机、发电机等需要将电缆直接连接在铜排上的设备，厂家需提供配套的螺栓、螺母、垫片。维的10/22福建东南造船有限公司tujfanSauthsfphmllainge.tTANo.：FSMW651-TA-E11-01Thesuitablebolts,nutsandwashersshouldbesuppliedbytheMakerfortheconnectionbetweencopperbusbarandYard'scable,suchasswitchboard.drivepropulsionmotorgenerator设备启动箱、控制箱、分电箱宽度大于600mm的需要做双开门。Ifthewidthsofstarters,controlcabinets,distributionboxesaremorethan600mm，doubledoorstobeinstalledonthecabinets驾控台上安装设备如有指示灯或者显示屏，必须带有调光装置。Dimmerstobesuppliedforallequipmentthatinstalledonthebridgecontrolconsolewhicharefittedwithindicatorsordisplays8）厂家需提供设备管路接口配对法兰或接头。DN32或以上的管路须用法兰或套管连接，DN32以下的管路须用法兰或套管或卡套接头。Allthecounterflangesorcounterconnectionsshouldbesuppliedbymaker，ifnootherspecialnote.PipesofDN32andovertobeflangeorsleeveconnected，pipeconnectionsbelowDN32aretobeflangedsleevedorbitetypetubefittings9）所有热工仪表的精度应不低于1.5级，并且在最大额定工作位置需用红线标记。使用在压力容器上的热工仪表需有法定检验机构签发的检验证书。所有泵进出口提供压力表/真空压力表。所有压力表都要配考克，温度计要有保护罩，所有PT100的探头都需要3线连接。Thetoleranceonthermalinstrumentsshallbewithintheaccuracyof1.5%.Themaximumratedparameteroninstrumentsshallbemarkedwitharedline.Allthermalinstrumentsusedonpressurevesselsshouldwithinspectionce
投标 / 标书制作要点（原创）
本汽雾笛涉及「招标公告」，投标方需重点关注：① 营业执照经营范围须含招标公告或对应服务类目；② 提供同类项目业绩证明；③ 报价方案与售后响应须明确；④ 紧盯投标截止与开标节点，建议提前完成标书制作与盖章。福建省项目常要求本地化服务能力与快速响应，务必在投标文件中凸显。
标书制作联系冯经理：17551026086
